Terms & Conditions

Effective Date: June 1, 2026

Welcome to SpaCCor ("Company", "we", "our", or "us"). These Terms & Conditions govern your access to and use of our website, products, and services. By accessing or using our website, you agree to comply with and be bound by these Terms & Conditions.

If you do not agree with any part of these terms, please discontinue use of our website and services.

1. About SpaCCor

SpaCCor provides interior design solutions, modular furniture services, renovation consultation, project planning, execution support, and related residential and commercial interior services.

2. Acceptance of Terms

By accessing our website, submitting inquiries, requesting quotations, or engaging our services, you acknowledge that you have read, understood, and agreed to these Terms & Conditions.

3. Services

SpaCCor offers consultation, design, planning, furnishing, renovation, project management, and execution services.

• All services are subject to availability.
• Project proposals are based on information provided by clients.
• We reserve the right to modify, suspend, or discontinue services at any time.

4. Quotations and Pricing

• All quotations are estimates based on the information available at the time.
• Prices may change due to material costs, taxes, scope modifications, or supplier changes.
• Additional client requests may result in revised pricing.
• Quotations remain valid only for the validity period specified in the proposal.

5. Project Execution

• Project timelines are estimates and may vary.
• Clients must provide accurate site details and necessary access.
• Delays caused by site conditions, approvals, suppliers, or clients may affect delivery schedules.
• SpaCCor will make reasonable efforts to complete projects within agreed timelines.

6. Payments

• Payments must be made according to the agreed project milestones.
• Late payments may delay project execution or result in service suspension.
• Applicable taxes will be charged as required by law.
• Ownership of supplied materials may remain with SpaCCor until full payment is received.

7. Client Responsibilities

Clients agree to:

• Provide accurate project information.
• Review and approve designs within reasonable timelines.
• Obtain any required permissions or approvals.
• Provide access to project locations as needed.
• Make payments according to agreed schedules.

8. Intellectual Property

All website content, concepts, drawings, designs, graphics, images, text, branding, and logos remain the intellectual property of SpaCCor unless otherwise stated.

No material may be copied, reproduced, distributed, or commercially used without prior written permission from SpaCCor.

9. Website Usage

You agree not to:

• Use the website for unlawful activities.
• Attempt unauthorized access to systems or servers.
• Upload malware, harmful software, or malicious content.
• Interfere with website security or functionality.
• Provide misleading or false information.

10. Third-Party Links

Our website may contain links to external websites. These links are provided for convenience only. SpaCCor is not responsible for the content, security, or privacy practices of third-party websites.

11. Limitation of Liability

To the maximum extent permitted by law:

• SpaCCor shall not be liable for indirect, incidental, or consequential damages.
• We do not guarantee uninterrupted or error-free website operation.
• We are not responsible for delays caused by suppliers, contractors, authorities, or force majeure events.

Any liability arising from our services shall be limited to the amount paid by the client for the specific service involved.

12. Warranties and Disclaimers

Our website and services are provided on an "as available" and "as is" basis.

While we strive to provide accurate information and professional services, we make no guarantees regarding:

• Website accuracy or completeness.
• Availability of services.
• Suitability of services for a specific purpose.
• Third-party product performance or availability.

13. Cancellation and Refunds

Cancellation and refund eligibility will be governed by the specific project agreement, quotation, or service contract.

Design fees, consultation charges, procurement costs, and completed work may be non-refundable unless otherwise agreed in writing.

14. Privacy

Your use of our website is also governed by our Privacy Policy, which explains how we collect, use, and protect personal information.

15. Force Majeure

SpaCCor shall not be liable for delays or failures caused by events beyond our reasonable control, including natural disasters, government restrictions, labor disputes, pandemics, transportation disruptions, power failures, or supply chain interruptions.

16. Governing Law

These Terms & Conditions shall be governed by and interpreted in accordance with the laws of India.

Any disputes arising from these Terms shall be subject to the exclusive jurisdiction of the courts located in Bengaluru, Karnataka, India.

17. Changes to Terms

We reserve the right to update or modify these Terms & Conditions at any time. Updates will be posted on this page with a revised effective date.

Continued use of the website following such changes constitutes acceptance of the revised Terms & Conditions.

18. Contact Information